Loading...
Serving North Palm Beach, FL and surrounding areas. (561) 356-8563
Effective date: January 1, 2026
By accessing or using the website at northpalmbeachsunroomsandpatios.com (the "Site"), or by engaging North Palm Beach Lanai Sunrooms & Patios ("we," "us," or "our") for any services, you agree to be bound by these Terms and Conditions. If you do not agree, please do not use the Site or engage our services. We may update these Terms from time to time, and your continued use constitutes acceptance of any changes.
North Palm Beach Lanai Sunrooms & Patios is a sunroom contractor serving North Palm Beach, FL and surrounding communities. Our services include but are not limited to: sunroom additions, four season sunrooms, three season sunrooms, patio enclosures, screen room installation, patio-to-sunroom conversions, deck-to-sunroom conversions, sunroom design, sunroom remodeling, and related outdoor living space construction.
All services are subject to a separate written contract or project agreement executed between you and North Palm Beach Lanai Sunrooms & Patios prior to the start of any work. These Terms apply to your use of the Site and are incorporated by reference into any written project agreement unless expressly superseded by that agreement.
Estimates provided through this Site, by phone, by email, or during an on-site consultation are non-binding and are subject to change until a written project agreement is executed by both parties. Estimates are based on information available at the time of the assessment and may be revised if the scope of work, site conditions, material costs, or permit requirements change.
All pricing is quoted in United States dollars and reflects the work described in the written estimate. Changes to the scope of work after execution of a written agreement may result in a change order, which must be agreed upon in writing before additional work proceeds.
We do not guarantee pricing found on third-party websites, directory listings, or other sources not directly issued by North Palm Beach Lanai Sunrooms & Patios. Contact us directly for current pricing relevant to your specific project.
Project start dates are subject to permit approval timelines, material availability, HOA review periods, and weather conditions. We will communicate scheduling updates as they arise. We are not liable for delays caused by government agencies, HOA review boards, material suppliers, or acts of nature.
Cancellation terms, including any applicable deposits or cancellation fees, are set forth in the written project agreement. If you cancel after a permit has been applied for, you may be responsible for permit fees already incurred.
We reserve the right to decline or discontinue services if site conditions, customer conduct, or safety concerns make it impractical or unsafe to continue the work.
Payment terms are set forth in the written project agreement and must be followed as specified. Typical payment structures involve a deposit at contract signing, progress payments tied to construction milestones, and a final payment upon substantial completion.
Failure to make payments as scheduled may result in a suspension of work. We reserve all legal remedies available under Florida law to collect unpaid balances, including the filing of a mechanics lien against the property where work was performed, as permitted by Florida Statutes.
All invoices are due upon receipt unless the written agreement specifies otherwise. Late payments may be subject to interest charges as permitted by applicable law.
Structural additions, including sunrooms and patio enclosures, require building permits under Florida law and North Palm Beach village ordinances. We manage the permit application process on your behalf as part of our standard services. You agree to cooperate with any reasonable request needed to complete permit applications, including signing documents and providing property information.
You agree not to occupy or use a new structure until all required inspections have been passed and the permit is closed. We are not liable for damages resulting from your use of an uninspected structure.
Warranty terms, if any, applicable to your specific project are set forth in the written project agreement. Unless expressly stated in the project agreement, all services and materials are provided on an "as is" basis.
To the maximum extent permitted by applicable law, we disclaim all implied warranties, including but not limited to implied warranties of merchantability or fitness for a particular purpose, with respect to the Site and its content.
Manufacturer warranties on materials and products installed as part of your project are the responsibility of the manufacturer and are passed through to you. We will assist in warranty claim coordination where commercially reasonable, but are not liable for manufacturer warranty decisions.
To the maximum extent permitted by applicable law, North Palm Beach Lanai Sunrooms & Patios shall not be liable for any indirect, incidental, consequential, special, or punitive damages arising from your use of the Site or from the performance of services, even if we have been advised of the possibility of such damages.
Our total liability to you for any claim arising out of or related to your use of the Site shall not exceed the amount you have paid to us in the twelve months preceding the claim, or one hundred US dollars, whichever is greater. This limitation does not apply to claims arising from our gross negligence or willful misconduct.
All content on this Site, including text, images, logos, and design elements, is the property of North Palm Beach Lanai Sunrooms & Patios or its licensors and is protected by applicable copyright and intellectual property laws. You may not reproduce, distribute, or use any content from this Site without our prior written permission.
In the event of a dispute arising from or related to these Terms or any project agreement, you agree to first attempt to resolve the dispute informally by contacting us directly. We will make a good-faith effort to resolve the issue within 30 days of receiving written notice of the dispute.
If informal resolution is unsuccessful, disputes shall be resolved through binding arbitration under the rules of the American Arbitration Association, conducted in Palm Beach County, Florida. The prevailing party in any arbitration or court proceeding shall be entitled to reasonable attorneys fees and costs, as permitted by applicable law.
Notwithstanding the foregoing, either party may seek injunctive or other equitable relief in a court of competent jurisdiction without first submitting to arbitration.
These Terms and Conditions are governed by and construed in accordance with the laws of the State of Florida, without regard to its conflict of law provisions. You consent to the exclusive jurisdiction of the state and federal courts located in Palm Beach County, Florida for any matters not subject to arbitration under these Terms.
We reserve the right to update or modify these Terms and Conditions at any time. Changes will be posted to this page with an updated effective date. Your continued use of the Site after changes are posted constitutes your acceptance of the revised Terms. We encourage you to review this page periodically.
Questions about these Terms and Conditions can be directed to us at:
North Palm Beach Lanai Sunrooms & Patios
412 Inlet Rd, North Palm Beach, FL 33408
Return to the home page, learn about us, or contact us.